1 / 11

Cancelling shipbuilding contracts – The dos and don’ts

Cancelling shipbuilding contracts – The dos and don’ts. William Cecil Partner Curtis Davis Garrard LLP 8 October 2012. B’s usual contractual cancellation rights. B entitled to cancel if: The vessel fails to meet specified performance guarantees Excessive delay Usual provisions for delay:

alder
Download Presentation

Cancelling shipbuilding contracts – The dos and don’ts

An Image/Link below is provided (as is) to download presentation Download Policy: Content on the Website is provided to you AS IS for your information and personal use and may not be sold / licensed / shared on other websites without getting consent from its author. Content is provided to you AS IS for your information and personal use only. Download presentation by click this link. While downloading, if for some reason you are not able to download a presentation, the publisher may have deleted the file from their server. During download, if you can't get a presentation, the file might be deleted by the publisher.

E N D

Presentation Transcript


  1. Cancelling shipbuilding contracts –The dos and don’ts William Cecil Partner Curtis Davis Garrard LLP 8 October 2012

  2. B’s usual contractual cancellation rights • B entitled to cancel if: • The vessel fails to meet specified performance guarantees • Excessive delay • Usual provisions for delay: • 30 days grace period • Liquidated damages at increasing daily rates up to a maximum of 210 days • Then B has right to cancel • Consequences of valid cancellation: • Refund of pre-delivery instalments • Interest • Damages for B’s losses cancelling shipbuilding contracts - the dos and don'ts

  3. Consequences of a wrongful cancellation • B in repudiatory breach • SY does not have to perform and can claim damages • Refund guarantee of no effect • B should consider whether possible/preferable to obtain award/judgment confirming that cancelling right has arisen before cancelling cancelling shipbuilding contracts - the dos and don'ts

  4. Extensions to cancelling date • May be extended due to: • Force majeure events • Other permissible delay • Variations • Cannot cancel before cancellation date even if inevitable that vessel will be late cancelling shipbuilding contracts - the dos and don'ts

  5. The Prevention Principle • B cannot insist on strict compliance of the contract if it has prevented SY from performing its obligations • B’s actions do not need to be a breach of contract • Consequences if no contractual mechanism to extend time: • Time will be “at large” • B will lose contractual cancellation right • Adyard Abu Dhabi v SD Marine Services [2011]: “A trivial variation may lead to the loss of the right to liquidated damages for a long period of culpable delay and, in this case, loss of the right to rescind as well.” cancelling shipbuilding contracts - the dos and don'ts

  6. Waiver • B must be careful not to waive its contractual right to cancel as a result of: • Delay • Actions inconsistent with B’s right to cancel • B should: • Reserve right to cancel as soon as right arises • Any subsequent correspondence or ongoing approvals should refer to reservation of rights letter • Cancel as soon as possible taking into account safety margin for possible extensions of time cancelling shipbuilding contracts - the dos and don'ts

  7. The refund guarantee • If unable to call on refund guarantee: • Credit risk - B will be an unsecured creditor of SY for claims for pre-paid instalments plus interest • Difficulties of enforcement of award/judgment in jurisdiction of SY • Points to check: • Expiry date of refund guarantee • Type of guarantee: “see to it” guarantee or on demand guarantee? • Rule in Holme v Brunskill cancelling shipbuilding contracts - the dos and don'ts

  8. Form of cancellation notice and demand on refund guarantee • Contractual requirements • Preserve right to claim damages in cancellation notice: Stocznia Gdynia SA v Gearbulk Holdings Ltd [2009] cancelling shipbuilding contracts - the dos and don'ts

  9. Assignment of the shipbuilding contract and the refund guarantee • Who is entitled to serve the cancellation notice and refund guarantee demand? • What consents are required to cancel/make demand? • Allow time to obtain bank’s consent cancelling shipbuilding contracts - the dos and don'ts

  10. Conclusion • Be fully prepared BEFORE you jump! cancelling shipbuilding contracts - the dos and don'ts

  11. CDG Knowledge Centrewww.cdg.co.uk cancelling shipbuilding contracts - the dos and don'ts

More Related