1 / 12

Terminations

Terminations. I won’t be back!. Termination for Default. Standard Clause Bases for Termination Failure to Deliver Timely Delivery Compliance with Specifications Failure to Make Progress Failure to Perform other Provisions Anticipatory Breach. Termination Decision.

inigo
Download Presentation

Terminations

An Image/Link below is provided (as is) to download presentation Download Policy: Content on the Website is provided to you AS IS for your information and personal use and may not be sold / licensed / shared on other websites without getting consent from its author. Content is provided to you AS IS for your information and personal use only. Download presentation by click this link. While downloading, if for some reason you are not able to download a presentation, the publisher may have deleted the file from their server. During download, if you can't get a presentation, the file might be deleted by the publisher.

E N D

Presentation Transcript

  1. Terminations I won’t be back!

  2. Termination for Default • Standard Clause • Bases for Termination • Failure to Deliver • Timely Delivery • Compliance with Specifications • Failure to Make Progress • Failure to Perform other Provisions • Anticipatory Breach

  3. Termination Decision • Contracting Officer Discretion • Improper Motive • Notices • Cure notice (10 days) • “Show cause”

  4. Contractor Defenses • Excusable Delay • Waiver of Due Date • Forbearance • Termination after Waiver

  5. Contractor Defenses • Excusable Delay • Acts of God • Acts of the Govt • Fires • Floods • Epidemics • Quarantine • Strikes • Freight Embargoes • Unusually Severe Weather

  6. Contractor Defenses • Excusable Delay Must be outside the control of the contractor • Unforeseeable • Unavoidable • Actual delay

  7. Government Remedies • Excess Costs or Re-procurement • Measure of Excess Costs • Similarity of Repurchase • Gov Duty to Mitigate • Gov Completion of Work • Other Remedies • Liquidated Damages

  8. Termination for Convenience • Government Right • Scope • Government Obligations • Written Notice • Post- Termination Duties • Contractor Obligations

  9. Constructive Termination • Conversion of Improper Default • Cancellation of Contract

  10. Termination Costs • Contractor Recovery • Settlement Proposal • Settlement Principles & Limits • Special Termination Costs • Pre-contract • Initial • Inventory • Post-termination

  11. Expenses • Settlement • Subcontractor Claims • Profit • Loss Adjustments

  12. Partial Terminations • Partial vs Deductive Change • Contractor Recovery

More Related